Terms of Use
Welcome to personalstudio. These Terms of Use govern your access to and use of our website and interior design services. By accessing or using our services, you agree to be bound by these terms.
Acceptance of Terms
By accessing this website or engaging our atmospheric interior design services, you acknowledge that you have read, understood, and agree to be bound by these Terms of Use and our Privacy Policy. If you do not agree with any part of these terms, please do not use our website or services.
Services Description
personalstudio provides professional interior design services including space analysis, atmospheric design planning, material selection, lighting design, texture composition, project coordination, and related consultation services. All design proposals and recommendations are customized based on client specifications and space requirements.
Client Responsibilities
When engaging our services, you agree to:
- Provide accurate information about your space, preferences, and project requirements
- Grant necessary access to the property for design assessment and implementation
- Make timely decisions regarding design proposals and material selections
- Ensure all required permits and approvals are obtained for construction or renovation work
- Make payments according to agreed schedules and terms
- Communicate any concerns or changes promptly
Design Process and Approvals
Our atmospheric design process involves multiple stages including consultation, space analysis, design development, and implementation. Client approval is required at key milestones before proceeding. Once approved, significant changes may incur additional fees. Final design outcomes depend on factors including existing space conditions, material availability, contractor execution, and client decisions.
Intellectual Property Rights
All design concepts, drawings, renderings, plans, and other creative materials developed by personalstudio remain our intellectual property. Clients receive a license to use approved designs for the specific project only. Reproduction, modification, or reuse of our designs for other projects requires written permission.
Website content, including text, graphics, logos, images, and software, is protected by copyright and other intellectual property laws. You may not reproduce, distribute, or create derivative works without our explicit written consent.
Photography and Marketing
With client consent, we may photograph completed projects for portfolio, marketing, and educational purposes. Clients will be notified before photography sessions and may decline or request limitations. We respect client privacy and will not disclose client names or specific locations without permission.
Payment Terms
Payment terms are specified in individual service agreements. Typically, projects require an initial deposit, progress payments at designated milestones, and final payment upon completion. Late payments may incur interest charges. We reserve the right to pause work on projects with outstanding payments.
Cancellation and Refunds
Cancellation policies vary by service package and project stage. Deposits are generally non-refundable as they cover initial consultation and design work. Clients may cancel ongoing projects with written notice, but will be responsible for work completed and expenses incurred. Please refer to your service agreement for specific cancellation terms.
Limitations of Liability
personalstudio provides design services and recommendations but is not responsible for construction defects, contractor errors, material defects, or structural issues beyond our control. We are not liable for delays caused by material availability, permit processes, or third-party contractors. Our liability is limited to the fees paid for our services.
Warranties and Disclaimers
We provide professional design services with reasonable care and skill. However, we make no warranties regarding specific outcomes, as results depend on multiple factors including client decisions, contractor execution, and existing conditions. Design recommendations are based on available information and professional judgment.
Third-Party Services
We may recommend contractors, suppliers, and vendors for project implementation. These third parties are independent businesses, and we are not responsible for their work quality, pricing, or performance. Clients enter separate agreements with third parties at their own discretion.
Dispute Resolution
Any disputes arising from our services will first be addressed through good-faith negotiation. If resolution cannot be reached, disputes will be subject to mediation before pursuing legal action. These terms are governed by the laws of Texas, United States.
Changes to Terms
We reserve the right to modify these Terms of Use at any time. Updated terms will be posted on our website with a revised "Last Updated" date. Continued use of our services after changes constitutes acceptance of modified terms.
Contact Information
For questions about these Terms of Use, please contact us:
personalstudio
25275 Budde Rd #17
Spring, TX 77380
United States
Phone: +1 832 370 5050
Email: clients@personalstudio.world